{"apiVersion":"1.0.0","budgetVersion":{"slug":"ppb2027","display_name":"Proposed UN Programme Budget for 2027, Peacekeeping Budget for 2026/2027 and Plan Outline 2026-2028","ppb_year":2027,"is_default":true,"sort_order":0},"coverage":["Budget citations describe recorded programme-budget references, not legal in-force status.","Missing extracted text does not establish that the original document contains no relevant provisions.","Resolution collections are related documents, not necessarily ordered versions or legal replacements.","Citation context is the selected budget cycle. Extraction and relationship coverage may be incomplete."],"document":{"symbol":"A/RES/74/272","title":"Construction of a New Facility for the International Residual Mechanism for Criminal Tribunals, Arusha Branch","issuingBody":"GA","year":2020,"documentType":"Resolutions","subjects":["International Criminal Courts","Conference Facilities","Construction","Arusha (United Republic of Tanzania)","United Republic of Tanzania"],"agendaItems":{"numbers":["147"],"titles":["Financing of the International Residual Mechanism for Criminal Tribunals."]},"sourceUrl":"https://documents.un.org/api/symbol/access?s=A%2FRES%2F74%2F272&l=en&t=pdf","pageUrl":"https://mandates.un.org/mandate/A/RES/74/272?ppb_version=ppb2027","canonicalUrl":"https://mandates.un.org/mandate/A/RES/74/272","jsonUrl":"https://mandates.un.org/mandate/A/RES/74/272.json?ppb_version=ppb2027","budgetVersion":"ppb2027","matchingCitationCount":0,"matchingEntityCount":0,"matchingEntities":[],"matchingFoundationalEntities":[],"matchingProgrammes":[],"matchingBudgetLocations":[],"series":{"is_collection":false,"has_newer":false,"is_latest":true,"series_count":7,"latest_version":"A/RES/74/272"},"group":null,"details":{"status":"included","citations":[],"budgetLocations":[],"foundationalEntities":[],"budgetLocationExpenditures":[],"entityCitationTotals":{},"entityExpenditures":{},"paragraphs":{"status":"available","language":"en","items":[{"extraction_quality_warning":false,"id":"da860253-ee08-5e4e-84a3-dab764a174a0","position":0,"note_ids":[],"note_references":[],"text":"Seventy-fourth session","type":"frontmatter","heading_level":null,"paragraph_type":null,"paragraph_level":null,"prefix":null,"links":[],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"3adfd362-ff8d-5d78-963b-00d9474ef407","position":1,"note_ids":[],"note_references":[],"text":"Agenda item 147","type":"frontmatter","heading_level":null,"paragraph_type":null,"paragraph_level":null,"prefix":null,"links":[],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"f4f73f1b-3eab-537c-9639-33425ebf938f","position":2,"note_ids":[],"note_references":[],"text":"Financing of the International Residual Mechanism for Criminal Tribunals","type":"frontmatter","heading_level":null,"paragraph_type":null,"paragraph_level":null,"prefix":null,"links":[],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"cc60eace-2a58-5c81-aa5d-ce04b337d240","position":3,"note_ids":[],"note_references":[],"text":"Resolution adopted by the General Assembly on 13 April 2020","type":"frontmatter","heading_level":null,"paragraph_type":null,"paragraph_level":null,"prefix":null,"links":[],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"bd3c10e1-9c85-550f-b2e0-5cd39751bc73","position":4,"note_ids":[],"note_references":[],"text":"[without reference to a Main Committee (A/74/L.55)]","type":"frontmatter","heading_level":null,"paragraph_type":null,"paragraph_level":null,"prefix":null,"links":[["A/74/L.55","https://undocs.org/en/A/74/L.55"]],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"c223d8ed-572b-5190-b1dc-42e1063dbd69","position":5,"note_ids":[],"note_references":[],"text":"Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch","type":"title","heading_level":null,"paragraph_type":null,"paragraph_level":null,"prefix":"74/272.","links":[],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"c4de3e1a-4f9c-5572-836d-c621e112619e","position":6,"note_ids":[],"note_references":[],"text":"The General Assembly,","type":"opening","heading_level":null,"paragraph_type":"preambular","paragraph_level":0,"prefix":null,"links":[],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"2965cd8f-2750-510c-b530-19314e4d82d1","position":7,"note_ids":[],"note_references":[],"text":"Recalling its resolutions 66/240 A of 24 December 2011, 66/240 B of 21 June 2012, 67/244 B of 12 April 2013, 68/257 of 27 December 2013, 68/267 of 9 April 2014, 69/276 of 2 April 2015, 70/258 of 1 April 2016, 71/282 of 6 April 2017, 72/270 of 4 April 2018 and 73/288 of 15 April 2019,","type":"paragraph","heading_level":null,"paragraph_type":"preambular","paragraph_level":1,"prefix":null,"links":[["66/240","https://undocs.org/en/A/RES/66/240"],["66/240 B","https://undocs.org/en/A/RES/66/240b"],["67/244 B","https://undocs.org/en/A/RES/67/244b"],["68/257","https://undocs.org/en/A/RES/68/257"],["68/267","https://undocs.org/en/A/RES/68/267"],["69/276","https://undocs.org/en/A/RES/69/276"],["70/258","https://undocs.org/en/A/RES/70/258"],["71/282","https://undocs.org/en/A/RES/71/282"],["72/270","https://undocs.org/en/A/RES/72/270"],["73/288","https://undocs.org/en/A/RES/73/288"]],"textWithHighlights":"*Recalling* its resolutions 66/240 A of 24 December 2011, 66/240 B of 21 June 2012, 67/244 B of 12 April 2013, 68/257 of 27 December 2013, 68/267 of 9 April 2014, 69/276 of 2 April 2015, 70/258 of 1 April 2016, 71/282 of 6 April 2017, 72/270 of 4 April 2018 and 73/288 of 15 April 2019,","mandates":[{"action_verb":"Recalling","action_verb_normalized":"recall","action_verb_type":"reinforcing","assignees":[],"mentioned_entities":[],"deliverables":[]}],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"c2d9fdf1-5638-54e4-b5bd-cd888fcacaa7","position":8,"note_ids":[1,2],"note_references":[{"offset":53,"note_id":1},{"offset":145,"note_id":2}],"text":"Having considered the report of the Secretary-General and the related report of the Advisory Committee on Administrative and Budgetary Questions,","type":"paragraph","heading_level":null,"paragraph_type":"preambular","paragraph_level":1,"prefix":null,"links":[],"textWithHighlights":"*Having considered* the report of the Secretary-General and the related report of the Advisory Committee on Administrative and Budgetary Questions,","mandates":[{"action_verb":"Having considered","action_verb_normalized":"consider","action_verb_type":"observing","assignees":[],"mentioned_entities":[],"deliverables":[]}],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"86345596-4a85-5994-adfb-6449e15350e0","position":9,"note_ids":[],"note_references":[],"text":"Takes note of the report of the Secretary-General;1","type":"paragraph","heading_level":null,"paragraph_type":"operative","paragraph_level":1,"prefix":"1.","links":[],"textWithHighlights":"*Takes note* of the report of the Secretary-General;1","mandates":[{"action_verb":"Takes note","action_verb_normalized":"take note","action_verb_type":"observing","assignees":[],"mentioned_entities":[],"deliverables":[]}],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"d18beffa-89cc-5038-8594-b131970a9977","position":10,"note_ids":[],"note_references":[],"text":"Endorses the conclusions and recommendations contained in the report of the Advisory Committee on Administrative and Budgetary Questions,2 subject to the provisions of the present resolution;","type":"paragraph","heading_level":null,"paragraph_type":"operative","paragraph_level":1,"prefix":"2.","links":[],"textWithHighlights":"*Endorses* the conclusions and recommendations contained in the report of the Advisory Committee on Administrative and Budgetary Questions,2 subject to the provisions of the present resolution;","mandates":[{"action_verb":"Endorses","action_verb_normalized":"endorse","action_verb_type":"deciding","assignees":[],"mentioned_entities":[],"deliverables":[]}],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"25109222-9166-554b-8b3a-bdbcd82a03d2","position":11,"note_ids":[],"note_references":[],"text":"Notes with appreciation the continued efforts of the Government of the United Republic of Tanzania in facilitating the construction project;","type":"paragraph","heading_level":null,"paragraph_type":"operative","paragraph_level":1,"prefix":"3.","links":[],"textWithHighlights":"*Notes* with appreciation the continued efforts of the Government of the United Republic of Tanzania in facilitating the construction project;","mandates":[{"action_verb":"Notes","action_verb_normalized":"note","action_verb_type":"observing","assignees":[],"mentioned_entities":[],"deliverables":[]}],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"36824449-92b2-51a0-9f6f-edbeb868d5c2","position":12,"note_ids":[],"note_references":[],"text":"Notes the progress made in the construction of the new premises, and requests the Secretary-General to submit a final report to the General Assembly during its seventy-sixth session;","type":"paragraph","heading_level":null,"paragraph_type":"operative","paragraph_level":1,"prefix":"4.","links":[],"textWithHighlights":"*Notes* the progress made in the construction of the new premises, and requests the Secretary-General to submit a final report to the General Assembly during its seventy-sixth session;","mandates":[{"action_verb":"Notes","action_verb_normalized":"note","action_verb_type":"observing","assignees":[],"mentioned_entities":[],"deliverables":[]}],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"dd9a2dde-5006-53af-a4bd-95b21d51352e","position":13,"note_ids":[],"note_references":[],"text":"Recalls paragraphs 10 and 26 of the report of the Advisory Committee, urges the Secretary-General to intensify his efforts to ensure full implementation of the project, including the remaining remediation works on the heating, ventilation and air conditioning system and pending closeout activities, without further delay, within the revised timelines and the total budget of 8,787,733 United States dollars approved for the project, and requests him to report thereon in the context of his final report;","type":"paragraph","heading_level":null,"paragraph_type":"operative","paragraph_level":1,"prefix":"5.","links":[],"textWithHighlights":"*Recalls* paragraphs 10 and 26 of the report of the Advisory Committee, urges the Secretary-General to intensify his efforts to ensure full implementation of the project, including the remaining remediation works on the heating, ventilation and air conditioning system and pending closeout activities, without further delay, within the revised timelines and the total budget of 8,787,733 United States dollars approved for the project, and requests him to report thereon in the context of his final report;","mandates":[{"action_verb":"Recalls","action_verb_normalized":"recall","action_verb_type":"reinforcing","assignees":[],"mentioned_entities":[],"deliverables":[]}],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"0ed57da7-2863-51d1-b74e-42fc672917df","position":14,"note_ids":[],"note_references":[],"text":"Requests the Secretary-General, in the context of his final report, to include, inter alia, an analysis of updated and comprehensive information on lessons learned and best practices, including areas of contract and project management, as well as knowledge gained during the ongoing implementation of the remaining project activities for application, as appropriate, to other construction projects;","type":"paragraph","heading_level":null,"paragraph_type":"operative","paragraph_level":1,"prefix":"6.","links":[],"textWithHighlights":"*Requests* <<the Secretary-General, in the context of his final report>>, to include, inter alia, an analysis of updated and comprehensive information on lessons learned and best practices, including areas of contract and project management, as well as knowledge gained during the ongoing implementation of the remaining project activities for application, as appropriate, to other construction projects;","mandates":[{"action_verb":"Requests","action_verb_normalized":"request","action_verb_type":"directive","assignees":[{"assignee":"the Secretary-General, in the context of his final report","assignee_normalized":"Secretary-General","assignee_type":"secretary-general"}],"mentioned_entities":[],"deliverables":[]}],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"7a41ca54-cde1-546d-8f23-ce0dde9e1e70","position":15,"note_ids":[],"note_references":[],"text":"Recalls paragraph 14 of the report of the Advisory Committee, and requests the Secretary-General to continue his efforts to pursue the recovery of the direct and indirect costs arising from errors and delays by contracting partners, namely the architect and the contractor, where economically feasible to do so, and to report thereon in the context of his final report;","type":"paragraph","heading_level":null,"paragraph_type":"operative","paragraph_level":1,"prefix":"7.","links":[],"textWithHighlights":"*Recalls* paragraph 14 of the report of the Advisory Committee, and requests the Secretary-General to continue his efforts to pursue the recovery of the direct and indirect costs arising from errors and delays by contracting partners, namely the architect and the contractor, where economically feasible to do so, and to report thereon in the context of his final report;","mandates":[{"action_verb":"Recalls","action_verb_normalized":"recall","action_verb_type":"reinforcing","assignees":[],"mentioned_entities":[],"deliverables":[]}],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"b217216f-8ee1-574e-b1ee-7b940fab04ad","position":16,"note_ids":[],"note_references":[],"text":"Notes with concern the intention of the contractor to contest the deduction in the amount of approximately 230,000 dollars from the final payment, and in this regard encourages the Secretary-General to make every effort to bring this matter to a swift conclusion;","type":"paragraph","heading_level":null,"paragraph_type":"operative","paragraph_level":1,"prefix":"8.","links":[],"textWithHighlights":"*Notes* with concern the intention of the contractor to contest the deduction in the amount of approximately 230,000 dollars from the final payment, and in this regard encourages the Secretary-General to make every effort to bring this matter to a swift conclusion;","mandates":[{"action_verb":"Notes","action_verb_normalized":"note","action_verb_type":"observing","assignees":[],"mentioned_entities":[],"deliverables":[]}],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"6f6805d1-7a57-53e6-b03c-d3bba09036d8","position":17,"note_ids":[],"note_references":[],"text":"Encourages the Secretary-General to continue his efforts to include local knowledge and capacity in the implementation of the project.","type":"paragraph","heading_level":null,"paragraph_type":"operative","paragraph_level":1,"prefix":"9.","links":[],"textWithHighlights":"*Encourages* <<the Secretary-General>> to continue his efforts to include local knowledge and capacity in the implementation of the project.","mandates":[{"action_verb":"Encourages","action_verb_normalized":"encourage","action_verb_type":"directive","assignees":[{"assignee":"the Secretary-General","assignee_normalized":"Secretary-General","assignee_type":"secretary-general"}],"mentioned_entities":[],"deliverables":[]}],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"242e5e76-2174-5f21-ad7d-0c48f7cc3045","position":18,"note_ids":[],"note_references":[],"text":"13 April 2020","type":"paragraph","heading_level":null,"paragraph_type":null,"paragraph_level":null,"prefix":null,"links":[],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"d970987c-bcdc-578c-93cf-a563387249bc","position":19,"note_ids":[1],"note_references":[],"text":"A/74/662.","type":"footnote","heading_level":null,"paragraph_type":null,"paragraph_level":null,"prefix":null,"links":[],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"},{"extraction_quality_warning":false,"id":"c7b2e5d8-fae1-5bd2-bc8b-b1bd702ccc85","position":20,"note_ids":[2],"note_references":[],"text":"A/74/707.","type":"footnote","heading_level":null,"paragraph_type":null,"paragraph_level":null,"prefix":null,"links":[],"section":"main","text_index":1,"parser_version":"sem-v5","source":"digitallibrary"}]},"versionHistory":{"series_count":7,"first_year":2014,"last_year":2020,"is_collection":false,"has_newer":false,"is_latest":true,"members":[{"document_symbol":"A/RES/74/272","text_metrics":{"comparison_unavailable_reason":"ordered","word_count":456,"previous_document_symbol":"A/RES/73/288","can_compare":true,"similarity_to_previous":0.4364035087719298},"title":"Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch","year":2020,"is_latest":true},{"document_symbol":"A/RES/73/288","text_metrics":{"comparison_unavailable_reason":"ordered","word_count":367,"previous_document_symbol":"A/RES/72/270","can_compare":true,"similarity_to_previous":0.38147138964577654},"title":"Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch","year":2019,"is_latest":false},{"document_symbol":"A/RES/72/270","text_metrics":{"comparison_unavailable_reason":"ordered","word_count":142,"previous_document_symbol":"A/RES/71/282","can_compare":true,"similarity_to_previous":0.9436619718309859},"title":"Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch","year":2018,"is_latest":false},{"document_symbol":"A/RES/71/282","text_metrics":{"comparison_unavailable_reason":"ordered","word_count":136,"previous_document_symbol":"A/RES/70/258","can_compare":true,"similarity_to_previous":0.36858006042296076},"title":"Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch","year":2017,"is_latest":false},{"document_symbol":"A/RES/70/258","text_metrics":{"comparison_unavailable_reason":"ordered","word_count":331,"previous_document_symbol":"A/RES/69/276","can_compare":true,"similarity_to_previous":0.32125205930807244},"title":"Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch","year":2016,"is_latest":false},{"document_symbol":"A/RES/69/276","text_metrics":{"comparison_unavailable_reason":"ordered","word_count":607,"previous_document_symbol":"A/RES/68/267","can_compare":true,"similarity_to_previous":0.4052718286655683},"title":"Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch","year":2015,"is_latest":false},{"document_symbol":"A/RES/68/267","text_metrics":{"comparison_unavailable_reason":"first","word_count":511,"previous_document_symbol":null,"can_compare":false,"similarity_to_previous":null},"title":"Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch","year":2014,"is_latest":false}],"latest_version":"A/RES/74/272"},"reports":{"status":"included","data":{"source":"union","data":{"pageOneAccepted":true,"reports":[{"report_recid":3850008,"symbols":["A/74/662"],"title":"Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch report of the Secretary-General","date_published":"2020-01-21","provenance":"catalogue_notes","catalogueAnnexOnly":false,"resolutionLinks":[{"symbol":"A/RES/73/288","provenance":"catalogue_notes","catalogueAnnexOnly":false}]},{"report_recid":1663210,"symbols":["A/73/718"],"title":"Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch report of the Secretary-General","date_published":"2019-01-22","provenance":"catalogue_notes","catalogueAnnexOnly":false,"resolutionLinks":[{"symbol":"A/RES/72/270","provenance":"catalogue_notes","catalogueAnnexOnly":false}]},{"report_recid":1472014,"symbols":["A/72/734"],"title":"Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch report of the Secretary-General","date_published":"2018-02-06","provenance":"catalogue_notes","catalogueAnnexOnly":false,"resolutionLinks":[{"symbol":"A/RES/71/282","provenance":"catalogue_notes","catalogueAnnexOnly":false}]},{"report_recid":858146,"symbols":["A/71/753"],"title":"Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch report of the Secretary-General","date_published":"2017-01-19","provenance":"catalogue_notes","catalogueAnnexOnly":false,"resolutionLinks":[{"symbol":"A/RES/70/258","provenance":"catalogue_notes","catalogueAnnexOnly":false}]}]}}},"relatedDocuments":{"status":"not_included"}}}}