Construction of a New Facility for the International Residual Mechanism for Criminal Tribunals, Arusha Branch

A/RES/74/272View PDF

Who adopted this document and its mandates?

A Resolution of the General Assembly, under agenda item 147 Financing of the International Residual Mechanism for Criminal Tribunals, published in 2020.

What other versions does this mandate have?

7 versions · 2014–2020

Year	Symbol	Title	Word length	Text similarity
2020	A/RES/74/272	Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch	456	44%Compare
2019	A/RES/73/288	Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch	367	38%Compare
2018	A/RES/72/270	Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch	142	94%Compare
2017	A/RES/71/282	Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch	136	37%Compare
2016	A/RES/70/258	Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch	331	32%Compare

Which reports were submitted under this mandate?

4 reports · 2017–2020

Year	Symbol	Title	Mandate resolution
2020	A/74/662	Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch report of the Secretary-General	A/RES/73/288
2019	A/73/718	Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch report of the Secretary-General	A/RES/72/270
2018	A/72/734	Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch report of the Secretary-General	A/RES/71/282
2017	A/71/753	Construction of a new facility for the International Residual Mechanism for Criminal Tribunals, Arusha branch report of the Secretary-General	A/RES/70/258

What subjects does this mandate have?

5 subjects

Arusha (United Republic of Tanzania)Conference Facilities Construction International Criminal Courts United Republic of Tanzania

What’s in this document?

9 operative paragraphs

Takes note of the report of the Secretary-General;1

Endorses the conclusions and recommendations contained in the report of the Advisory Committee on Administrative and Budgetary Questions,2 subject to the provisions of the present resolution;

Notes with appreciation the continued efforts of the Government of the United Republic of Tanzania in facilitating the construction project;

Notes the progress made in the construction of the new premises, and requests the Secretary-General to submit a final report to the General Assembly during its seventy-sixth session;

Recalls paragraphs 10 and 26 of the report of the Advisory Committee, urges the Secretary-General to intensify his efforts to ensure full implementation of the project, including the remaining remediation works on the heating, ventilation and air conditioning system and pending closeout activities, without further delay, within the revised timelines and the total budget of 8,787,733 United States dollars approved for the project, and requests him to report thereon in the context of his final report;

Requests the Secretary-General, in the context of his final report, to include, inter alia, an analysis of updated and comprehensive information on lessons learned and best practices, including areas of contract and project management, as well as knowledge gained during the ongoing implementation of the remaining project activities for application, as appropriate, to other construction projects;

Recalls paragraph 14 of the report of the Advisory Committee, and requests the Secretary-General to continue his efforts to pursue the recovery of the direct and indirect costs arising from errors and delays by contracting partners, namely the architect and the contractor, where economically feasible to do so, and to report thereon in the context of his final report;

Notes with concern the intention of the contractor to contest the deduction in the amount of approximately 230,000 dollars from the final payment, and in this regard encourages the Secretary-General to make every effort to bring this matter to a swift conclusion;

Encourages the Secretary-General to continue his efforts to include local knowledge and capacity in the implementation of the project.

13 April 2020

Who adopted this document and its mandates?

What other versions does this mandate have?

Which reports were submitted under this mandate?

What subjects does this mandate have?

What’s in this document?

Table of contents